Okaloosa County BOCC — February 18, 2014 — Underground Electric Manhole — reading text

or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under para- graph 12.01.B.2, on the basis of the Cost of the Work (determined as provided in paragraph 11.01) plus a CONTRACTOR’s fee for overhead and profit (deter- mined as provided in paragraph 12.01.C). C. CONTRACTOR’s Fee: The CONTRACTOR’s fee for overhead and profit shall be determined as follows: 1. amutually acceptable fixed fee; or 2. ifa fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: GENERAL CONDITIONS OKALOOSA COUNTY WATER AND SEWER DATE: 5/13/2012 00700-34 Russell Stephenson — Electrical Manhole Rehabilitation SECTION 00700 GENERAL CONDITIONS a. for costs incurred under paragraphs 11.01.A.1 and 11.01.A.2, the CONTRACTOR’s fee shall be 15 percent; b. for costs incurred under paragraph 11.01.A.3, the CONTRACTOR’s fee shall be five percent; c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of paragraph 12.01.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under paragraphs 11.01.A.1 and 11.01.A.2 and that any higher tier Subcontractor and CONTRACTOR will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under paragraphs 11.01.A.4, 11.01.A.5, and 11.01.B; e. the amount of credit to be allowed by CONTRACTOR to OWNER for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in CONTRACTOR’s fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are in- volved in any one change, the adjustment in CONTRACTOR’ fee shall be computed on the basis of the net change in accordance with para- graphs 12.01.C.2.a through 12.01.C.2.e, inclu- sive. 12.02 Change of Contract Times A. The Contract Times (or Milestones) may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contract Times (or Milestones) shall be based on written notice submitted by the party making the claim to the ENGINEER and the other party to the Contract in accordance with the provisions of paragraph 10.05. B. Any adjustment of the Contract Times (or Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be determined in accordance with the provisions of this Article 12. Russell Stephenson — Electrical Manhole Rehabilitation 12.03 Delays Beyond CONTRACTOR ’s Control A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of CONTRACTOR, the Contract Times (or Milestones) will be extended in an amount equal to the time lost due to such delay if'a Claim is made therefor as provided in paragraph 12.02.A. Delays beyond the control of CON- TRACTOR shall include, but not be limited to, acts or neglect by OWNER, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. 12.04 Delays Within CONTRACTOR’s Control A. The Contract Times (or Milestones) will not be extended due to delays within the control of CONTRACTOR. Delays attributable to and within the control ofa Subcontractor or Supplier shall be deemed to be delays within the control of CONTRACTOR. 12.05 Delays Beyond OWNER’s and CONTRACTOR'S Control A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of both OWNER and CONTRACTOR, an extension of the Contract Times (or Milestones) in an amount equal to the time lost due to such delay shall be CONTRACTOR’s sole and exclusive remedy for such delay. 12.06 Delay Damages A. In no event shall OWNER or ENGINEER be liable to CONTRACTOR, any Subcontractor, any Supplier, or any other person or organization, or to any surety for or employee or agent of any of them, for damages arising out of or resulting from: 1. delays caused by or within the control of CONTRACTOR; or 2. delays beyond the control of both OWNER and CONTRACTOR including but not limited to fires, floods, epidemics, abnormal weather conditions, acts of God, or acts or neglect by utility owners or other contractors performing other work as contemplated by Article 7. B. Nothing in this paragraph 12.06 bars a change in Contract Price pursuant to this Article 12 to compensate GENERAL CONDITIONS OKALOOSA COUNTY WATER AND SEWER DATE: 5/13/2012 00700-35 SECTION 00700 GENERAL CONDITIONS CONTRACTOR due to delay, interference, or disruption directly attributable to actions or inactions of OWNER or anyone for whom OWNER is responsible. ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which OWNER or ENGINEER has actual knowledge will be given to CONTRACTOR. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. OWNER, ENGINEER, ENGINEER’s Con- sultants, other representatives and personnel of OWNER, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their obser- vation, inspecting, and testing. CONTRACTOR shall provide them proper and safe conditions for such access and advise them of CONTRACTOR’s Site safety procedures and programs so that they may comply therewith as applicable. 13.03 Tests and Inspections A. CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. OWNER shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by paragraphs [3.03.C and 13.03.D below; 2. that costs incurred in connection with tests or inspections conducted pursuant to paragraph 13.04.B shall be paid as provided in said paragraph 13.04.B; and 3. as otherwise specifically provided in the Contract Documents. Russell Stephenson — Electrical Manhole Rehabilitation C. IfLaws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, CONTRACTOR shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish ENGINEER the required certificates of inspec- tion or approval. D. CONTRACTOR shall be responsible for arranging and obtaining and shall pay all costs in connec- tion with any inspections, tests, or approvals required for OWNER’s and ENGINEER’s acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to CONTRACTOR’s purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to OWNER and ENGINEER. E. Ifany Work (or the work of others) that is to be inspected, tested, or approved is covered by CONTRACTOR without written concurrence of ENGINEER, it must, if requested by ENGINEER, be uncovered for observation. F. Uncovering Work as provided in paragraph 13.03.E shall be at CONTRACTOR’s expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR’s intention to cover the same and ENGINEER has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of ENGINEER, it must, if requested by ENGINEER, be uncovered for ENGINEER’s observation and replaced at CONTRACTOR’s expense. B. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or inspected or tested by others, CONTRACTOR, at ENGINEER’s request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as ENGINEER may require, that portion of the Work in question, furnishing all necessary labor, materi- al, and equipment. If it is found that such Work is defective, CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute GENERAL CONDITIONS OKALOOSA COUNTY WATER AND SEWER 00700-36 DATE: 5/13/2012 SECTION 00700 GENERAL CONDITIONS resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decrease in the Contract Price. Ifthe parties are unable to agree as to the amount thereof, OWNER may make a Claim therefor as provided in paragraph 10.05. If, however, such Work is not found to be defective, CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Times (or Milestones), or both, directly attribut- able to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 13.05 OWNER May Stop the Work A. Ifthe Work is defective, or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, OWNER may order CONTRACTOR to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of OWNER to stop the Work shall not give rise to any duty on the part of OWNER to exercise this right for the benefit of CONTRACTOR, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. CONTRACTOR shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by ENGINEER, remove it from the Project and replace it with Work that is not defective. CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). 13.07 Correction Period A. If within one year after the date of Substantial Completion or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, or if the Russell Stephenson — Electrical Manhole Rehabilitation repair of any damages to the land or areas made available for CONTRACTOR’s use by OWNER or permitted by Laws and Regulations as contemplated in paragraph 6.11.A is found to be defective, CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER’s written instructions: (i) repair such